Terms & Conditions
Terms & Conditions
Terms & Conditions
Last updated: September, 2025
Last updated: September, 2025
These Terms & Conditions (“Terms”) govern your use of the PunchZero website (www.punchzero.pro) and all services we provide as an electrical subcontractor. By accessing our website, submitting a proposal, or engaging our services, you agree to these Terms.
These Terms & Conditions (“Terms”) govern your use of the PunchZero website (www.punchzero.pro) and all services we provide as an electrical subcontractor. By accessing our website, submitting a proposal, or engaging our services, you agree to these Terms.
1. Services
PunchZero, Inc. provides electrical subcontracting services with a focus on retail and commercial tenant improvement (TI) projects. Our services may include but are not limited to:
Preparation and submission of electrical proposals and bids Installation of electrical systems, fixtures, and wiring
Coordination with general contractors and project managers
Safety compliance and project documentation
PunchZero, Inc. provides electrical subcontracting services with a focus on retail and commercial tenant improvement (TI) projects. Our services may include but are not limited to:
Preparation and submission of electrical proposals and bids Installation of electrical systems, fixtures, and wiring
Coordination with general contractors and project managers
Safety compliance and project documentation
2. Proposals and Estimates
All proposals are based on information available at the time of submission.
Proposals are subject to revision if the project scope, drawings, or requirements change. Unless otherwise stated, proposals are valid only for the period specified in the document. Acceptance of a proposal constitutes acknowledgment of the scope, pricing, and terms outlined in the submission.
All proposals are based on information available at the time of submission.
Proposals are subject to revision if the project scope, drawings, or requirements change. Unless otherwise stated, proposals are valid only for the period specified in the document. Acceptance of a proposal constitutes acknowledgment of the scope, pricing, and terms outlined in the submission.
3. Client Responsibilities
By engaging PunchZero, clients agree to:
Provide accurate and complete project details, drawings, and specifications.
Ensure timely access to the job site for inspections, installations, or other necessary work.
Maintain compliance with all applicable safety standards and legal requirements. Notify PunchZero promptly of any changes in scope, schedule, or requirements.
By engaging PunchZero, clients agree to:
Provide accurate and complete project details, drawings, and specifications.
Ensure timely access to the job site for inspections, installations, or other necessary work.
Maintain compliance with all applicable safety standards and legal requirements. Notify PunchZero promptly of any changes in scope, schedule, or requirements.
4. Payment Terms
Payment schedules, milestones, and due dates are specified in project agreements or contracts.
Late payments may be subject to interest charges as permitted by law.
PunchZero reserves the right to suspend services in the event of non-payment.
Payment schedules, milestones, and due dates are specified in project agreements or contracts.
Late payments may be subject to interest charges as permitted by law.
PunchZero reserves the right to suspend services in the event of non-payment.
5. Intellectual Property
All content on the PunchZero website, including text, design, branding, logos, and images, is the property of PunchZero and may not be copied, distributed, or reproduced without prior written consent.
All content on the PunchZero website, including text, design, branding, logos, and images, is the property of PunchZero and may not be copied, distributed, or reproduced without prior written consent.
6. Limitation of Liability
PunchZero will exercise reasonable care and skill in providing services. However, we are not liable for:
Indirect, incidental, or consequential damages
Losses arising from delays caused by factors outside our control (e.g., weather, supplier delays, regulatory approvals) Errors or omissions based on inaccurate or incomplete information provided by clients
PunchZero will exercise reasonable care and skill in providing services. However, we are not liable for:
Indirect, incidental, or consequential damages
Losses arising from delays caused by factors outside our control (e.g., weather, supplier delays, regulatory approvals) Errors or omissions based on inaccurate or incomplete information provided by clients
7. Third-Party Links
Our website may contain links to third-party websites. These are provided for convenience only, and PunchZero is not responsible for the content, security, or practices of those external sites.
Our website may contain links to third-party websites. These are provided for convenience only, and PunchZero is not responsible for the content, security, or practices of those external sites.
8. Governing Law
These Terms are governed by and interpreted in accordance with the laws of the State of California. Any disputes shall be resolved exclusively in the courts of Los Angeles County, California.
These Terms are governed by and interpreted in accordance with the laws of the State of California. Any disputes shall be resolved exclusively in the courts of Los Angeles County, California.
9. Modifications
PunchZero reserves the right to update or modify these Terms at any time without prior notice. Updates will be posted on this page with a revised “last updated” date. Your continued use of our website or services indicates acceptance of the revised Terms.
PunchZero reserves the right to update or modify these Terms at any time without prior notice. Updates will be posted on this page with a revised “last updated” date. Your continued use of our website or services indicates acceptance of the revised Terms.
10. Contact Us
If you have any questions about these Terms, please contact us at:
PunchZero Inc.
175 E Olive Ave, Ste 200
Burbank, CA 91502
Email: bids@punchzero.pro
Phone: (747) 356-8344
If you have any questions about these Terms, please contact us at:
PunchZero Inc.
175 E Olive Ave, Ste 200
Burbank, CA 91502
Email: bids@punchzero.pro
Phone: (747) 356-8344
Add us to your vendor list
Add us to your vendor list
Please complete the brief form below, and we will promptly forward our full qualifications package